Terms & Conditions
1. Key Terms
1.1 Services provided by www.psdtomanythings.com,
www.psdtomanythings.com shall provide the services as nominated at time of order. A copy of these agreed services will be emailed to both parties at the beginning of the project, after we have received your completely filled order form and project files.
1.2 Delivery of the Services
- Start date: PSD To Manythings will provide services from the first business day after the date of purchase.
- Completion date: PSD To Manythings shall provide the completion date after reviewing all of the files and details of the project.
- Delays: PSD To Manythings aims to deliver all the projects on time, but if unforeseen circumstances occur, the delivery may get delayed, PSD To Manythings will endeavor to offer some form of compensation up to the value of the original project cost. You are not entitled to make any further claims against PSD To Manythings beyond the original cost of the project.
1.3 Format of Project Delivery
PSD To Manythings shall provide the completed service in form of a .zip file upon completion of the project. In the case that you have requested some other specific form of delivery, PSD To Manythings will comply with this request if agreed on the contract.
1.4 Prices
As consideration for the provision of the services by the PSD To Manythings, the price these services are nominated at the time of purchase and it varies depending on the services requested. For a correct pricing please refer to your invoice emailed at time of purchase and make sure you agree with the quote provided before accepting the contract.
1.5 Payment
You agree to pay the price agreed to PSD To Manythings before we begin working on your project. Any charges payable under this Agreement are inclusive of any applicable taxes, tariff surcharges or other like amounts assessed by any governmental entity arising as a result of the provision of the services provided by PSD To Manythings to you under this Agreement and such will be payable by the person that contracts PSD To Manythings in addition to all other charges payable here under.
2. General terms
2.2 Term and Termination
PSD To Manythings agrees to grant to the purchaser a Non-Disclosure Agreement (NDA) where PSD To Manythings promises that any material, information, files related your project will not be shared with third parties or used in any other way that is not related to the completion of the project. In respect of the material specifically created for the Purchaser as part of the services, PSD To Manythings accepts that the full title guarantee belongs to the person or company that contracted our services and all of the copyright, other intellectual property rights and any other data or material used or subsisting in the project files, whether finished or unfinished also belongs to the purchaser.
2.3 Relationship of the Parties
The Parties acknowledge and agree that PSD to HTML services performed by PSD To Manythings, its employees or agents shall be as an independent contractor and that nothing in this Agreement shall be deemed to constitute a partnership, joint venture, agency relationship or otherwise between the parties.
2.4 Miscellaneous
The failure of either party to enforce its rights under this Agreement at any time for any period shall not be construed as a waiver of such rights and if any part, term or provision of this Agreement is held to be illegal or unenforceable neither the validity or enforceability of the remainder of this Agreement shall be affected.
- Neither Party shall assign or transfer all or any part of its rights under this Agreement without the consent of the other Party.
- This Agreement may not be amended for any other reason without the prior written agreement of both Parties.
- This Agreement constitutes the entire understanding between the Parties PSD to HTML services and/or platform implementation hereof unless any representation or warranty made about this Agreement was made fraudulently and, save as may be expressly referred to or referenced herein, supersedes all prior representations, writings, negotiations or understandings with respect hereto.
- This Agreement constitutes the entire understanding between the Parties PSD to HTML services and/or platform implementation hereof unless any representation or warranty made about this Agreement was made fraudulently and, save as may be expressly referred to or referenced herein, supersedes all prior representations, writings, negotiations or understandings with respect hereto.
- This Agreement shall be governed by the laws of the jurisdiction in which the Purchaser is located (or if the Purchaser is based in more than one country, the country in which its headquarters are located) (the “Territory”) and the parties agree to submit disputes arising out of or in connection with this Agreement to the non-exclusive of the courts in the Territory.
3. Refund Policy
We give you refund only in following circumstances:
- Your request to cancel the order is received before the order is initialized.
- In case of CMS Implementation, no refund shall be given if the theme is uploaded on client’s server
- For orders below $300, complete refund shall be provided. For orders above $300, the refund amount will be mutually discussed and then refund will be processed
4. Edits Terms
After preview, if you approve the HTML/CSS, you are more than welcome to provide changes that you need done in order for the project to be fully
pixel perfect based on your PSD files. You will have 3 rounds of edits (for example: font styling, minor alignment changes, JS effects) and if you
require a change in the design that might require extra efforts, we may have to charge an additional fee.
A round can be defined as a list of edits that we are going to complete. Once the first round is fully completed, if you need a few more changes you will be able to send a second round and a third round if needed.
The programmer will need a detailed list of changes (screenshots if possible) so we can provide a fast and efficient result.
This screenshot tool may be helpful: http://awesomescreenshot.com/
After the 3 rounds of edits are finalized you can ask for more changes, but this will be charged
separately.
If your project is CMS read below:
Edits on the CMS have the same flow as the HTML process, but they are only related to functionality (for example: change widgets, use a different plugins, the logic of the code) and not HTML/CSS because we will be using the HTML code that you previously approved.
Upon making payment for one of PSDToManythings’ services you are hereby accepting this terms and services agreement.
5. Intellectual Property Rights
You will be the owner of HTML Mock Ups / CMS Themes and PHP code developed by PSD To Manythings for you or your clients project. However you will own the intellectual property rights only after the complete payment is made. In case, you download the files from server without making a complete payment, it will be dimmed unethical and in such a case PSD To Manythings will be the owner of the code. If you download the files and host it on your clients server without making a complete payment to PSD To Manythings, then both you and your client will be responsible for the theft of code and the hosting account / website / domain may be reported to DMCA for usage of code developed by PSD To Manythings and you may also be asked to take down the site.